The Customer’s attention is particularly drawn to the provisions of clause 15 (Limitation of liability).
The following definitions and rules of interpretation apply in these Conditions.
Agreed Delivery Date: has the meaning given in clause 4.2.
Business Day: a day other than a Saturday, Sunday or public holiday in England, when banks in London are open for business.
Commencement Date: has the meaning given in clause 2.2.
Conditions: these terms and conditions as amended from time to time in accordance with clause 19.8.
Contract: the contract between the Supplier and the Customer for the supply of Goods and/or Services in accordance with these Conditions.
Control: has the meaning given in section 1124 of the Corporation Tax Act 2010, and the expression change of control shall be construed accordingly.
Controller and processor: as defined in the Data Protection Legislation.
Customer: the person or firm who purchases the Goods and/or Services from the Supplier.
Customer Default: has the meaning given in clause 9.2.
Data Protection Legislation: the UK Data Protection Legislation and any other European Union legislation relating to personal data and all other legislation and regulatory requirements in force from time to time which apply to a party relating to the use of personal data (including, without limitation, the privacy of electronic communications); and the guidance and codes of practice issued by the relevant data protection or supervisory authority and applicable to a party.
Delivery Location: has the meaning given in clause 4.2.
Force Majeure Event: has the meaning given to it in clause 18.
Goods: the goods (or any part of them) set out in the Order.
Goods Specification: any specification for the Goods, including any relevant plans or drawings, that is agreed in writing by the Customer and the Supplier.
Intellectual Property Rights: patents, utility models, rights to inventions, copyright and neighbouring and related rights, moral rights, trade marks and service marks, business names and domain names, rights in get-up and trade dress, goodwill and the right to sue for passing off or unfair competition, rights in designs, rights in computer software, database rights, rights to use, and protect the confidentiality of, confidential information (including know-how and trade secrets), and all other intellectual property rights, in each case whether registered or unregistered and including all applications and rights to apply for and be granted, renewals or extensions of, and rights to claim priority from, such rights and all similar or equivalent rights or forms of protection which subsist or will subsist now or in the future in any part of the world.
Order: the Customer’s order for the supply of Goods and/or Services, as set out in the Proposal.
Proposal: the Supplier’s written quotation and scope of work in connection with the Goods and Services.
Services: the product commissioning service, to be supplied by the Supplier to the Customer as detailed in the Order.
Service Specification: the description or specification for the Services provided in writing by the Supplier to the Customer.
Supplier: Commercial Hot Water Solutions Limited registered in England and Wales with company number 08588497.
UK Data Protection Legislation: all applicable data protection and privacy legislation in force from time to time in the UK including the General Data Protection Regulation ((EU) 2016/679); the Data Protection Act 2018; the Privacy and Electronic Communications Directive (2002/58/EC) (as updated by Directive 2009/136/EC) and the Privacy and Electronic Communications Regulations 2003 (SI 2003/2426) as amended.
(a) A person includes a natural person, corporate or unincorporated body (whether or not having separate legal personality).
(b) A reference to a party includes its personal representatives (where applicable), successors and permitted assigns.
(c) A reference to a statute or statutory provision is a reference to it as amended or re-enacted. A reference to a statute or statutory provision includes all subordinate legislation made under that statute or statutory provision.
(d) Any words following the terms including, include, in particular, for example or any similar expression shall be construed as illustrative and shall not limit the sense of the words, description, definition, phrase or term preceding those terms.
(e) A reference to writing or written includes email but not fax.
2. Basis of contract
2.1 The Order constitutes an offer by the Customer to purchase Goods and/or Services in accordance with these Conditions.
2.2 The Order shall only be deemed to be accepted when the Supplier issues written acceptance of the Order at which point and on which date the Contract shall come into existence (Commencement Date).
2.3 Any samples, drawings, descriptive matter or advertising issued by the Supplier and any descriptions of the Goods or illustrations or descriptions of the Services contained in the Supplier’s catalogues, brochures, sales material, website or the Proposal are issued or published for the sole purpose of giving an approximate idea of the Services and/or Goods described in them. They shall not form part of the Contract or have any contractual force.
2.4 These Conditions apply to the Contract to the exclusion of any other terms that the Customer seeks to impose or incorporate, or which are implied by law, trade custom, practice or course of dealing.
2.5 Any quotation given by the Supplier shall not constitute an offer, and is only valid for a period of 60 Days from its date of issue.
2.6 All of these Conditions shall apply to the supply of both Goods and Services except where application to one or the other is specified.
3.1 The Goods are described in the Goods Specification.
3.2 The Supplier reserves the right to amend the Goods Specification if required by any applicable statutory or regulatory requirement, and the Supplier shall notify the Customer in any such event.
4. Delivery of Goods
4.1 The Supplier shall ensure that:
(a) each delivery of the Goods is accompanied by a delivery note which shows the date of the Order, all relevant Customer and Supplier reference numbers, the type and quantity of the Goods (including the code number of the Goods, where applicable), special storage instructions (if any) and, if the Order is being delivered by instalments, the outstanding balance of Goods remaining to be delivered; and
(b) it states clearly on the delivery note any requirement for the Customer to return any packaging material to the Supplier. The Customer shall make any such packaging materials available for collection at such times as the Supplier shall reasonably request. Returns of packaging materials shall be at the Supplier’s expense.
4.2 The Supplier shall deliver the Goods to the location set out in the Order or such other location as the parties may agree (Delivery Location) and the Supplier shall contact the Customer to agree a delivery date when the Goods are ready (Agreed Delivery Date).
4.3 Once scheduled for delivery, the Delivery Location and Agreed Delivery Date cannot be changed save with the written agreement of the Supplier.
4.4 Any special delivery instructions must be included in the Order.
4.5 Delivery of the Goods shall be completed on the arrival of the Goods at the Delivery Location which shall be kerbside via a suitable vehicle. The Customer shall be responsible for unloading the Goods including providing suitable machinery, equipment and personnel.
4.6 Any dates quoted for delivery of the Goods in the order are approximate only, and the time of delivery is not of the essence. The Supplier shall not be liable for any delay in delivery of the Goods that is caused by a Force Majeure Event or the Customer’s failure to provide the Supplier with adequate delivery instructions or any other instructions that are relevant to the supply of the Goods.
4.7 If the Supplier fails to deliver the Goods, its liability shall be limited to the costs and expenses incurred by the Customer in obtaining replacement goods of similar description and quality in the cheapest market available, less the price of the Goods. The Supplier shall have no liability for any failure to deliver the Goods to the extent that such failure is caused by a Force Majeure Event or the Customer’s failure to provide the Supplier with adequate delivery instructions for the Goods or any relevant instruction related to the supply of the Goods or any breach of clauses 4.4 or 4.5.
4.8 If the Customer fails to take delivery of the Goods on the Agreed Delivery Date, then except where such failure or delay is caused by a Force Majeure Event or by the Supplier’s failure to comply with its obligations under the Contract in respect of the Goods:
(a) delivery of the Goods shall be deemed to have been completed at 9.00 am on the third Business Day following the Agreed Delivery Date; and
(b) the Supplier shall store the Goods until delivery takes place, and charge the Customer for all related costs and expenses (including insurance).
4.9 If ten Business Days after the Agreed Delivery Date the Customer has not taken delivery of them, the Supplier may invoice in full the items, storage charges and redelivery costs.
4.10 The Supplier may deliver the Goods by instalments, which shall be invoiced and paid for separately. Each instalment shall constitute a separate contract. Any delay in delivery or defect in an instalment shall not entitle the Customer to cancel any other instalment.
5. Quality of Goods
5.1 The Supplier warrants that on delivery, and for a period of 12 months from the date of delivery, the Goods shall:
(a) conform in all material respects with their description and any applicable Goods Specification;
(b) be free from material defects in design, material and workmanship;
(c) be of satisfactory quality (within the meaning of the Sale of Goods Act 1979); and
(d) be fit for any purpose held out by the Supplier.
5.2 Full warranty terms and conditions which apply to Goods can be found on the Supplier’s website at https://chwsltd.co.uk/warranty/ which are incorporated into these conditions.
5.3 The Customer shall examine the Goods on delivery. The Customer may reject any Goods delivered to it that do not comply with clause 5.1 or 5.2, provided that:
(a) notice of rejection is given to the Supplier:
(i) in the case of a defect that is apparent on normal visual inspection, on delivery in accordance with clause 4; or
(ii) in the case of a latent defect, within a reasonable time of the latent defect having become apparent,
(b) none of the events listed in clause 5.6 apply.
5.4 If the Customer fails to give notice of rejection in accordance with clause 5.3, it shall be deemed to have accepted the Goods.
5.5 Subject to clause 5.6, the Supplier shall, at its option, repair or replace the defective Goods, or refund the price of the defective Goods in full if:
(a) the Customer gives notice in writing in accordance with clause 5.3;
(b) the Supplier is given a reasonable opportunity of examining such Goods; and
(c) the Customer (if asked to do so by the Supplier) returns such Goods to the Supplier’s place of business at the Customer’s cost and risk.
5.6 The Supplier shall not be liable for the Goods’ failure to comply with the warranties in clauses 5.1 and 5.2 if:
(a) the Customer makes any further use of such Goods after giving a notice in accordance with clause 5.3;
(b) the defect arises because the Customer failed to follow the Supplier’s oral or written instructions as to the storage, installation, commissioning, use or maintenance of the Goods or (if there are none) good trade practice;
(c) the defect arises as a result of the Supplier following any drawing, design or Goods Specification supplied by the Customer;
(d) the Customer alters or repairs such Goods without the written consent of the Supplier;
(e) the defect arises as a result of fair wear and tear, wilful damage, negligence, or abnormal working conditions; or
(f) the Goods differ from the Goods Specification as a result of changes made to ensure they comply with applicable statutory or regulatory standards.
5.7 Except as provided in this clause 5, the Supplier shall have no liability to the Customer in respect of the Goods’ failure to comply with the warranties in clauses 5.1 and 5.2.
5.8 The terms of these Conditions shall apply to any repaired or replacement Goods supplied by the Supplier.
6. Return of non-defective Goods
6.1 The following clauses shall apply to any Goods which are non-defective.
6.2 A request to return non-defective Goods must be notified to the Supplier within 5 Business Days of delivery. Acceptance of the return of non-defective Goods shall be at the absolute discretion of the Supplier.
6.3 If a return of non-defective Goods is accepted, the Goods must be returned to the Supplier within 10 Business Days of the Supplier notifying the Customer that they will accept the return. The cost and risk of returning non-defective Goods to the Supplier shall be borne by the Customer.
6.4 Standard catalogue Goods of which the Supplier accepts return shall be refunded by way of a credit note (which shall not include any delivery costs) less a 30% restocking fee.
6.5 Non-defective bespoke, manufactured or non-catalogue Goods are not returnable.
7. Title and risk
7.1 The risk in the Goods shall pass to the Customer on arrival of the Goods at the Delivery Location.
7.2 Title to the Goods shall not pass to the Customer until the Supplier receives payment in full (in cash or cleared funds) for the Goods and any other goods that the Supplier has supplied to the Customer in respect of which payment has become due, in which case title to the Goods shall pass at the time of payment of all such sums.
7.3 Until title to the Goods has passed to the Customer, the Customer shall:
(a) store the Goods separately from all other goods held by the Customer so that they remain readily identifiable as the Supplier’s property;
(b) not remove, deface or obscure any identifying mark or packaging on or relating to the Goods;
(c) maintain the Goods in satisfactory condition and keep them insured against all risks for their full price on the Supplier’s behalf from the date of delivery;
(d) notify the Supplier immediately if it becomes subject to any of the events listed in clause 16.2(b) to clause 16.2(d); and
(e) give the Supplier such information relating to the Goods as the Supplier may require from time to time.
7.4 If before title to the Goods passes to the Customer the Customer becomes subject to any of the events listed in clause 16.2(b) to clause 16.2(d), then, without limiting any other right or remedy the Supplier may have at any time:
(a) require the Customer to deliver up all Goods in its possession which have not been resold, or irrevocably incorporated into another product; and
(b) if the Customer fails to do so promptly, enter any premises of the Customer or of any third party where the Goods are stored in order to recover them.
8. Supply of Services
8.1 The Supplier shall supply the Services to the Customer in accordance with the Service Specification in all material respects.
8.2 The Supplier shall use all reasonable endeavours to meet any performance dates for the Services specified in the Order, but any such dates shall be estimates only and time shall not be of the essence for the performance of the Services.
8.3 The Supplier reserves the right to amend the Service Specification if necessary to comply with any applicable law or regulatory requirement, or if the amendment will not materially affect the nature or quality of the Services, and the Supplier shall notify the Customer in any such event.
8.4 The Supplier warrants to the Customer that the Services will be provided using reasonable care and skill.
9. Customer’s obligations
9.1 The Customer shall:
(a) ensure that the terms of the Order are complete and accurate;
(b) co-operate with the Supplier in all matters relating to the Services;
(c) provide the Supplier, its employees, agents, consultants and subcontractors, with access to the Customer’s premises, office accommodation and other facilities as reasonably required by the Supplier to provide the Services;
(d) provide the Supplier with such information and materials as the Supplier may reasonably require in order to supply the Services, and ensure that such information is complete and accurate in all material respects;
(e) ensure that the Customer’s premises are in suitable state and condition for the supply of the Services;
(f) if applicable, obtain and maintain all necessary licences, permissions and consents which may be required for the Services before the date on which the Services are to start; and
(g) comply with all applicable laws, including health and safety laws.
9.2 If the Supplier’s performance of any of its obligations under the Contract is prevented or delayed by any act or omission by the Customer or failure by the Customer to perform any relevant obligation (Customer Default):
(a) without limiting or affecting any other right or remedy available to it, the Supplier shall have the right to suspend performance of the Services until the Customer remedies the Customer Default, and to rely on the Customer Default to relieve it from the performance of any of its obligations in each case to the extent the Customer Default prevents or delays the Supplier’s performance of any of its obligations;
(b) the Supplier shall not be liable for any costs or losses sustained or incurred by the Customer arising directly or indirectly from the Supplier’s failure or delay to perform any of its obligations as set out in this clause 9.2; and
(c) the Customer shall reimburse the Supplier on written demand for any costs or losses sustained or incurred by the Supplier arising directly or indirectly from the Customer Default.
10. Charges and payment
10.1 The price for Goods and Services:
(a) shall be the price set out in the Order or, if no price is quoted, the price set out in the Supplier’s published price list as at the date of the Order; and
(b) shall be inclusive of all costs and charges of packaging, insurance and transport of the Goods which shall be invoiced to the Customer.
10.2 The Supplier reserves the right to increase the price of the Goods, by giving notice to the Customer at any time before delivery, to reflect any increase in the cost of the Goods to the Supplier that is due to:
(a) any factor beyond the control of the Supplier (including foreign exchange fluctuations, increases in taxes and duties, and increases in labour, materials and other manufacturing costs);
(b) any request by the Customer to change the Delivery Location, delivery date(s), quantities or types of Goods ordered, or the Goods Specification; or
(c) any delay caused by any instructions of the Customer in respect of the Goods or failure of the Customer to give the Supplier adequate or accurate information or instructions in respect of the Goods.
10.3 In respect of Goods, the Supplier shall invoice the Customer on or at any time after completion of delivery. In respect of Services, the Supplier shall invoice the Customer on completion of the Services.
10.4 The Customer shall pay each invoice submitted by the Supplier:
(a) within 30 days following the end of the month in which the invoice was raised or in accordance with any credit terms agreed by the Supplier and confirmed in writing to the Customer; and
(b) in full and in cleared funds to a bank account nominated in writing by the Supplier,
time for payment shall be of the essence of the Contract.
10.5 All amounts payable by the Customer under the Contract are exclusive of amounts in respect of value added tax chargeable from time to time (VAT). Where any taxable supply for VAT purposes is made under the Contract by the Supplier to the Customer, the Customer shall, on receipt of a valid VAT invoice from the Supplier, pay to the Supplier such additional amounts in respect of VAT as are chargeable on the supply of the Services or Goods at the same time as payment is due for the supply of the Services or Goods.
10.6 If the Customer fails to make a payment due to the Supplier under the Contract by the due date, then, without limiting the Supplier’s remedies under clause 16 (Termination), the Customer shall pay interest on the overdue sum from the due date until payment of the overdue sum, whether before or after judgment. Interest under this clause 10.6 will accrue each day at 5% a year above the Bank of England’s base rate from time to time, but at 5% a year for any period when that base rate is below 0%.
10.7 All amounts due under the Contract shall be paid in full without any set-off, counterclaim, deduction or withholding (other than any deduction or withholding of tax as required by law).
11. Intellectual property rights
All Intellectual Property Rights in or arising out of or in connection with the Services shall be owned by the Supplier.
12. Data protection
Both parties will comply with all applicable requirements of the Data Protection Legislation. This clause 12 is in addition to, and does not relieve, remove or replace, a party’s obligations or rights under the Data Protection Legislation.
13.1 The parties acknowledge that for the purposes of the Data Protection Legislation, the Customer is the controller and the Supplier is the processor.
13.2 Without prejudice to the generality of clause 12, the Customer will ensure that it has all necessary appropriate consents and notices in place to enable lawful transfer of the personal data to the Supplier for the duration and purposes of the Contract.
13.3 Either party may, at any time on not less than 30 days’ notice, revise this clause 13 by replacing it with any applicable controller to processor standard clauses or similar terms forming part of an applicable certification scheme (which shall apply when replaced by attachment to the Contract).
14.1 Each party undertakes that it shall not at any time disclose to any person any confidential information concerning the business, affairs, customers, clients or suppliers of the other party, except as permitted by clause 14.2.
14.2 Each party may disclose the other party’s confidential information:
(a) to its employees, officers, representatives, subcontractors or advisers who need to know such information for the purposes of carrying out the party’s obligations under the Contract. Each party shall ensure that its employees, officers, representatives, subcontractors or advisers to whom it discloses the other party’s confidential information comply with this clause 14; and
(b) as may be required by law, a court of competent jurisdiction or any governmental or regulatory authority.
14.3 Neither party shall use the other party’s confidential information for any purpose other than to perform its obligations under the Contract.
15. Limitation of liability: THE CUSTOMER’S ATTENTION IS PARTICULARLY DRAWN TO THIS CLAUSE.
15.1 The Supplier has obtained insurance cover in respect of its own legal liability for individual claims not exceeding £5,000,000 per claim.
15.2 The restrictions on liability in this clause 15 apply to every liability arising under or in connection with the Contract including liability in contract, tort (including negligence), misrepresentation, restitution or otherwise.
15.3 Nothing in the Contract limits any liability which cannot legally be limited, including but not limited to liability for:
(a) death or personal injury caused by negligence;
(b) fraud or fraudulent misrepresentation; and
(c) breach of the terms implied by section 12 of the Sale of Goods Act 1979 or section 2 of the Supply of Goods and Services Act 1982 (title and quiet possession).
15.4 Subject to clause 15.3, the Supplier’s total liability to the Customer shall not exceed the total charges (being all sums paid by the Customer and all sums payable under the Contract in respect of goods and services actually supplied by the Supplier, whether or not invoiced to the Customer) in the previous 12-month period commencing with the Commencement Date or any anniversary.
15.5 Without prejudice to clause 15.4, neither party shall under any circumstances whatsoever be liable to the other, whether in contract, tort (including negligence) or restitution, or for breach of statutory duty or misrepresentation, or otherwise, for any:
(a) loss of profit; or
(b) loss of goodwill; or
(c) loss of business; or
(d) loss of business opportunity; or
(e) loss of anticipated saving; or
(f) special, indirect or consequential damage,
suffered by the other party that arises under or in connection with the Contract.
15.6 The Supplier has given commitments as to compliance of the Goods and Services with relevant specifications in clause 5 and clause 8. In view of these commitments, the terms implied by sections 13 to 15 of the Sale of Goods Act 1979 and sections 3, 4 and 5 of the Supply of Goods and Services Act 1982 are, to the fullest extent permitted by law, excluded from the Contract.
15.7 Unless the Customer notifies the Supplier that it intends to make a claim in respect of an event within the notice period, the Supplier shall have no liability for that event. The notice period for an event shall start on the day on which the Customer became, or ought reasonably to have become, aware of the event having occurred and shall expire 6 months from that date. The notice must be in writing and must identify the event and the grounds for the claim in reasonable detail.
15.8 This clause 15 shall survive termination of the Contract.
16.1 Save in the cause of Orders comprising bespoke or manufactured Goods, without affecting any other right or remedy available to it, either party may terminate the Contract by giving the other party not less than three months’ written notice.
16.2 Without affecting any other right or remedy available to it, either party may terminate the Contract with immediate effect by giving written notice to the other party if:
(a) the other party commits a material breach of its obligations under the Contract and (if such breach is remediable) fails to remedy that breach within 10 days after receipt of notice in writing to do so;
(b) the other party takes any step or action in connection with its entering administration, provisional liquidation or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business;
(c) the other party suspends, or threatens to suspend, or ceases or threatens to cease to carry on all or a substantial part of its business; or
(d) the other party’s financial position deteriorates to such an extent that in the terminating party’s opinion the other party’s capability to adequately fulfil its obligations under the Contract has been placed in jeopardy.
16.3 Without affecting any other right or remedy available to it, the Supplier may terminate the Contract with immediate effect by giving written notice to the Customer if:
(a) the Customer fails to pay any amount due under the Contract on the due date for payment; or
(b) there is a change of Control of the Customer.
16.4 Without affecting any other right or remedy available to it, the Supplier may suspend the supply of Services or all further deliveries of Goods under the Contract or any other contract between the Customer and the Supplier if the Customer fails to pay any amount due under the Contract on the due date for payment, the Customer becomes subject to any of the events listed in clause 16.2(b) to clause 16.2(d), or the Supplier reasonably believes that the Customer is about to become subject to any of them.
17. Consequences of termination
17.1 On termination of the Contract:
(a) the Customer shall immediately pay to the Supplier all of the Supplier’s outstanding unpaid invoices and interest and, in respect of Services and Goods supplied but for which no invoice has been submitted, the Supplier shall submit an invoice, which shall be payable by the Customer immediately on receipt; and
(b) the Customer shall return all Goods which have not been fully paid for. If the Customer fails to do so, then the Supplier may enter the Customer’s premises and take possession of them. Until they have been returned, the Customer shall be solely responsible for their safe keeping and will not use them for any purpose not connected with this Contract.
17.2 Termination of the Contract shall not affect any rights, remedies, obligations and liabilities of the parties that have accrued up to the date of termination, including the right to claim damages in respect of any breach of the Contract which existed at or before the date of termination.
17.3 Any provision of the Contract that expressly or by implication is intended to have effect after termination shall continue in full force and effect.
18. Force majeure
Neither party shall be in breach of the Contract nor liable for delay in performing or failure to perform, any of its obligations under the Contract if such delay or failure result from events, circumstances or causes beyond its reasonable control (a Force Majeure Event).
19.1 Assignment and other dealings
(a) The Supplier may at any time assign, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any or all of its rights and obligations under the Contract.
(b) The Customer shall not assign, transfer, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any of its rights and obligations under the Contract without the prior written consent of the Supplier.
(a) Any notice or other communication given to a party under or in connection with the Contract shall be in writing and shall be:
(i) delivered by hand or by pre-paid first-class post or other next working day delivery service at its registered office (if a company) or its principal place of business (in any other case); or
(ii) sent by email to the address notified by one party to the other in writing.
(b) Any notice or communication shall be deemed to have been received:
(i) if delivered by hand, on signature of a delivery receipt;
(ii) if sent by pre-paid first-class post or other next working day delivery service, at 9.00 am on the second Business Day after posting or at the time recorded by the delivery service; and
(iii) if sent by email, at the time of transmission, or, if this time falls outside business hours in the place of receipt, when business hours resume. In this clause 19.2(b)(iii), business hours means 9.00am to 5.00pm Monday to Friday on a day that is not a public holiday in the place of receipt.
(c) This clause 19.2 does not apply to the service of any proceedings or other documents in any legal action or, where applicable, any arbitration or other method of dispute resolution.
19.3 Severance. If any provision or part-provision of the Contract is or becomes invalid, illegal or unenforceable, it shall be deemed modified to the minimum extent necessary to make it valid, legal and enforceable. If such modification is not possible, the relevant provision or part-provision shall be deemed deleted. Any modification to or deletion of a provision or part-provision under this clause 19.3 shall not affect the validity and enforceability of the rest of the Contract.
19.4 Waiver. A waiver of any right or remedy under the Contract or by law is only effective if given in writing and shall not be deemed a waiver of any subsequent right or remedy. A failure or delay by a party to exercise any right or remedy provided under the Contract or by law shall not constitute a waiver of that or any other right or remedy, nor shall it prevent or restrict any further exercise of that or any other right or remedy. No single or partial exercise of any right or remedy provided under the Contract or by law shall prevent or restrict the further exercise of that or any other right or remedy.
19.5 No partnership or agency. Nothing in the Contract is intended to, or shall be deemed to, establish any partnership or joint venture between the parties, constitute either party the agent of the other, or authorise either party to make or enter into any commitments for or on behalf of the other party.
19.6 Entire agreement
(a) The Contract constitutes the entire agreement between the parties and supersedes and extinguishes all previous agreements, promises, assurances, warranties, representations and understandings between them, whether written or oral, relating to its subject matter.
(b) Each party acknowledges that in entering into the Contract it does not rely on, and shall have no remedies in respect of any statement, representation, assurance or warranty (whether made innocently or negligently) that is not set out in the Contract. Each party agrees that it shall have no claim for innocent or negligent misrepresentation or negligent misrepresentation based on any statement in the Contract.
(c) Nothing in this clause shall limit or exclude any liability for fraud.
19.7 Third party rights.
(a) Unless it expressly states otherwise, the Contract does not give rise to any rights under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of the Contract.
(b) The rights of the parties to rescind or vary the Contract are not subject to the consent of any other person.
19.8 Variation. Except as set out in these Conditions, no variation of the Contract shall be effective unless it is agreed in writing and signed by the parties (or their authorised representatives).
19.9 Governing law. The Contract and any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with it or its subject matter or formation shall be governed by and construed in accordance with the law of England and Wales.
19.10 Jurisdiction. Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.